Need to file a complaint?
BBB is here to help. We'll guide you through the process.
Complaint Details
Note that complaint text that is displayed might not represent all complaints filed with BBB. See details.
Initial Complaint
06/15/2023
- Complaint Type:
- Delivery Issues
- Status:
- Answered
Our community contracted with this company to fix our pool. Promised date 5/26 now no open date. Only 1 person working on it for weeks and the company is unresponsive and wont commit to a date to open.Business response
06/25/2023
Unfortunately we have had a spring with erratic weather. We have completed the portions of the job that are able to be performed- the concrete chipping and plastered were delayed by the sheer number of rain days through May and June. Those out all jobs on delay and we have to wait for concrete crews to be able to get to these jobs. Weve depended on subs to do the majority of the project and as such we need to rely on their availability.
the job has now been completed. It was a highly customized job done for a much lower price than the product the community has been given. it is behind schedule but we could do little too nothing with the curve ***** Mother Nature threw this season. There were many many portions and pieces to the job that were worked on through the winter and spring and also some hold *** by other contractors. i think you will find the pool has been completed beautifully. Unfortunately in renovation and construction some things are out of our control. We apologize for the inconvenience in the timing.
We as a company do not like delays either. Much of this was outside of our control
we have been in communication with the board and management company through this process. unfortunately some community members may be saying things to the contrary. Finally, it has not been one person working on the pool. It may sometimes be one person working at a time. Understand that with stones and plaster large crews are needed for proper completion and because of weather delays we were only now able to get the necessary crew to complete the project
*Some consumers may elect to not publish the details of their complaints, some complaints may not meet BBB's standards for publication, or BBB may display a portion of complaints when a high volume is received for a particular business. ↩
BBB Business Profiles may not be reproduced for sales or promotional purposes.
BBB Business Profiles are provided solely to assist you in exercising your own best judgment. BBB asks third parties who publish complaints, reviews and/or responses on this website to affirm that the information provided is accurate. However, BBB does not verify the accuracy of information provided by third parties, and does not guarantee the accuracy of any information in Business Profiles.
When considering complaint information, please take into account the company's size and volume of transactions, and understand that the nature of complaints and a firm's responses to them are often more important than the number of complaints.
BBB Business Profiles generally cover a three-year reporting period. BBB Business Profiles are subject to change at any time. If you choose to do business with this business, please let the business know that you contacted BBB for a BBB Business Profile.
As a matter of policy, BBB does not endorse any product, service or business. Businesses are under no obligation to seek BBB accreditation, and some businesses are not accredited because they have not sought BBB accreditation.
Customer Reviews are not used in the calculation of BBB Rating
Contact Information
7173 S Havana St Ste A600-128
Centennial, CO 80112-3891
Business hours
Today,Closed
MMonday | 9:00 AM - 5:00 PM |
---|---|
TTuesday | 9:00 AM - 5:00 PM |
WWednesday | 9:00 AM - 5:00 PM |
ThThursday | 9:00 AM - 5:00 PM |
FFriday | 9:00 AM - 5:00 PM |
SaSaturday | Closed |
SuSunday | Closed |
Want a quote from this business?
Get a QuoteCustomer Complaints Summary
1 total complaints in the last 3 years.
0 complaints closed in the last 12 months.