ComplaintsforG and C Contracting, LLC
Need to file a complaint?
BBB is here to help. We'll guide you through the process.
Complaint Details
Note that complaint text that is displayed might not represent all complaints filed with BBB. See details.
Initial Complaint
05/10/2023
- Complaint Type:
- Order Issues
- Status:
- Answered
I entered into a contract with G&C Contracting to complete work on ***************'s new salon at ******************************* The total contract value was $279, 279. To date $132,150 has been billed for and paid.The contract was fully executed on 10/18/2022 and work was supposed to begin, per my request on 10/20/2022 as permits had already been approved. The construction schedule had a project completion date of 1/3/2023 and the contract itself stated that the "Contractor will make its best efforts to complete the Work within 13 weeks of receipt of the construction permit for the Work ". To this date, the construction has been behind due neglect from the contractor. Materials have been ordered late, workers are frequently not on site, there is no full time onsite supervisor, work does not get started nor completed for weeks, and the contractor frequently does not communicate with me. Attached is a more comprehensive list of breaches but below is the key one:Pursuit to section 5.b of our signed contract Contractor shall submit a detailed schedule for performance of the contract, in a form acceptable to Owner/s, which shall comply with all scheduling requirements of the Contract Documents and with Paragraph 6.a above- Contractor has still not submitted an updated, detailed schedule. The one submitted last year gave a completion date of January 3rd. Contractor is now over 12 weeks behind schedule without giving me any estimated completion date. Week over week I have requested an updates schedule and have not gotten any response on this request. On February 17th I again requested feedback on hard dates for when things might be completed. On February 21st I requested that the contractor use all of his efforts to complete the project as swiftly as possible and he has still not addressed my concern directly, nor given me an updated schedule. In an act of good faith, I have not yet terminated the contractor but will if contractor is unable to finish the job in the next 2 weeksBusiness response
05/19/2023
Contractor has all the proof and back-ups of the responses, including: pictures, videos, invoices, checks, dates, drawings, sub-contractor's correspondences and all the other Responding Claims by the Contractor.
*Some consumers may elect to not publish the details of their complaints, some complaints may not meet BBB's standards for publication, or BBB may display a portion of complaints when a high volume is received for a particular business. ↩
BBB Business Profiles may not be reproduced for sales or promotional purposes.
BBB Business Profiles are provided solely to assist you in exercising your own best judgment. BBB asks third parties who publish complaints, reviews and/or responses on this website to affirm that the information provided is accurate. However, BBB does not verify the accuracy of information provided by third parties, and does not guarantee the accuracy of any information in Business Profiles.
When considering complaint information, please take into account the company's size and volume of transactions, and understand that the nature of complaints and a firm's responses to them are often more important than the number of complaints.
BBB Business Profiles generally cover a three-year reporting period. BBB Business Profiles are subject to change at any time. If you choose to do business with this business, please let the business know that you contacted BBB for a BBB Business Profile.
As a matter of policy, BBB does not endorse any product, service or business. Businesses are under no obligation to seek BBB accreditation, and some businesses are not accredited because they have not sought BBB accreditation.
Customer Reviews are not used in the calculation of BBB Rating
Customer Complaints Summary
1 total complaints in the last 3 years.
0 complaints closed in the last 12 months.